THIS AGREEMENT (“Agreement”) is entered into on the date indicated in the “Website Project Agreement”, between Tandos Marketing (“Developer”) and The Organization Filled in the “Website Project Agreement Form” (“Client”), and shall be effective as of the date filled by the client (the “Effective Date”) or emailed the go ahead by client.

Recitals

WHEREAS, Developer is engaged in the business of the design and implementation of Internet web sites,

WHEREAS, Client desires to retain Developer for the design and implementation of the web site set forth herein,

NOW THEREFORE, Developer and Client agree as follows:

Scope of Services

Developer agrees to design and implement a web site for Client in accordance with the specifications set forth in “Exhibit A” (“YOUR WEBSITE REQUIREMENTS”).

Price and Payment Terms

Client will pay Developer for the Development Services according to the terms and time frames for completion set forth in “Exhibit B” ( “PROJECT PLAN”) and / or “Exhibit C” (the “WEBSITE INVESTMENT”).

Term and Termination

Unless terminated as provided herein, this Agreement will extend to and terminate upon completion of the Development Services. Either party may terminate this Agreement without cause upon seven (7) days written notice. In the event of termination without cause, Client agrees to pay Developer for all Development Services performed up to the date of termination. In the event of termination by Client without cause within the first fifteen (15) days of project execution, Client agrees to pay Developer thirty (30) percent of the contract amount in addition to Development Services performed up to the date of termination. Either party may terminate this agreement for material breach, provided, however, that the terminating party has given the other party at least seven (7) days written notice of and the opportunity to cure the breach. Termination for breach will not preclude the terminating party from exercising any other remedies for breach.
Ownership of Intellectual Property

Developer has licensed to client certain intellectual property for use in the development of the Web Site that is the subject of a certain license agreement for the technologies used (WordPress, Google Analytics and more) provided by third party companies. To the extent that Developer has received payment of compensation as provided in this Agreement, Developer hereby assigns to Client all right, title, and interest in any other intellectual property created or developed by Developer for Client under this agreement. Client hereby grants to Developer authoring and portfolio rights for the Website; specifically to place a “designed by” logo/text on the bottom of each page of the Web Site as well as unrestricted use of the Website in the Developer’s portfolio and marketing collateral.

Confidential Information

All information relating to Client that is known to be confidential or proprietary, or which is clearly marked as such, will be held in confidence by Developer and will not be disclosed or used by Developer except to the extent that such disclosure or use is reasonably necessary to the performance of the Development Services.

information relating to Developer that is known to be confidential or proprietary, or which is clearly marked as such, will be held in confidence by Client and will not be disclosed or used by Client except to the extent that such disclosure or use is reasonably necessary to the performance of Client’s duties and obligations under this Agreement.

These obligations of confidentiality will extend for a period of one (1) year after the termination of this agreement, but will not apply with respect to information that is independently developed by the parties, lawfully becomes a part of the public domain, or of which the parties gained knowledge or possession free of any confidentiality obligation.
Warranty and Disclaimer
Developer warrants that the Development Services will be provided in a workmanlike manner, and in conformity with generally prevailing industry standards. THIS WARRANTY IS EXCLUSIVE AND IS IN LIEU OF ALL OTHER WARRANTIES, WHETHER EXPRESS OR IMPLIED, INCLUDING ANY WARRANTIES OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE AND ANY ORAL OR WRITTEN REPRESENTATIONS, PROPOSALS OR STATEMENTS MADE ON OR PRIOR TO THE EFFECTIVE DATE OF THIS AGREEMENT.

Limitation of Remedies

Client’s sole and exclusive remedy for any claim against Developer with respect to the quality of the Development Services will be the correction by Developer of any material defects or deficiencies therein, of which Client notifies Developer in writing within thirty (30) days after the completion of that portion of the Development Services. In the absence of any such notice, the Development Services will be deemed satisfactory to and accepted by Client.

Limitation of Liability

In no event will Developer be liable for any loss of profit or revenue by Client, or for any other consequential, incidental, indirect or economic damages incurred or suffered by Client arising as a result of or related to the Development Services, whether in contract, tort or otherwise, even if Client has advised of the possibility of such loss or damages. Client further agrees that the total liability of the Developer for all claims of any kind arising as a result of or related to this Agreement, or to any act or omission of Developer, whether in contract, tort or otherwise, will not exceed an amount equal to the amount actually paid by Client to Developer for the Development Services during the twelve (12) month period preceding the date the claim arises. Client will indemnify and hold Developer harmless against any claims by third parties, including all costs, expenses and attorneys’ fees incurred by Developer therein, arising out of or in conjunction with Client’s performance under or breach of this Agreement. Client warrants and represents that it is the rightful owner or licensee of all content that it may provide to Developer for implementation on the web site. Client will indemnify and hold Developer harmless against any claims for infringement of intellectual property, including but not limited to infringement of any copyright, trademark, patent or trade secret made against Developer by any third party.

Relation of Parties

The performance by Developer of its duties and obligations under this Agreement will be that of an independent contractor, and nothing herein will create or imply an agency relationship between Developer and Client, nor will this Agreement be deemed to constitute a joint venture or partnership between the parties.

Employee Solicitation/Hiring

During the period of this agreement and for twelve (12) months thereafter, neither party will directly or indirectly solicit or offer employment to or hire any employee, former employee, subcontractor, or former subcontractor of the other. The terms “former employee” and “former subcontractor” will include only those employees or subcontractors of either party who were employed or utilized by that party on the Effective Date of this Agreement.

Non-assignment

Neither party will assign this Agreement, in whole or in part, without the prior written consent of the other party. This Agreement will inure to the benefit of, and be binding upon the parties hereto, together with their respective legal representatives, successors, and assigns, as permitted herein.

Arbitration

Any dispute arising under this Agreement will be subject to binding arbitration by a single Arbitrator with the Chartered Institute of Arbitrators (Kenya Chapter), in accordance with its relevant industry rules, if any. The parties agree that this Agreement will be governed by and construed and interpreted in accordance with the laws of Kenya. The arbitration will be held in Nairobi. The Arbitrator will have the authority to grant injunctive relief and specific performance to enforce the terms of this Agreement. Judgment on any award rendered by the Arbitrator may be entered in any Court of competent jurisdiction.

Severability

If any term of this Agreement is found to be unenforceable or contrary to law, it will be modified to the least extent necessary to make it enforceable, and the remaining portions of this Agreement will remain in full force and effect.

Force Majeur

Neither party will be held responsible for any delay or failure in performance of any part of this Agreement to the extent that such delay is caused by events or circumstances beyond the delayed party’s reasonable control.

No Wavier

The waiver by any party of any breach of covenant will not be construed to be a waiver of any succeeding breach or any other covenant. All waivers must be in writing, and signed by the party waiving its rights. This Agreement may be modified only by a written instrument executed by authorized representatives of the parties hereto.

Entire Agreement

This Agreement together with any attachments referred to herein constitute the entire agreement between the parties with respect to its subject matter, and supersedes all prior agreements, proposals, negotiations, representations or communications relating to the subject matter. Both parties acknowledge that they have not been induced to enter into this Agreement by any representations or promises not specifically stated herein.

IN WITNESS WHEREOF, the parties have executed this Agreement by their duly authorized representatives.